Billion Dollar Boondoggle Act This act requires the Office of Management and Budget (OMB) to collect information from federal agencies and report to Congress regarding projects that are behind schedule or have expenditures that have exceeded the original cost estimate. Specifically, the act requires OMB to issue guidance directing federal agencies to annually submit specified information to OMB regarding certain federally funded projects that (1) are more than five years behind schedule, or (2) have expenditures that are at least $1 billion more than the original cost estimate for the project. Among other information, the agencies must submit to OMB a description of each project; an explanation of any change to the original scope of the project; the original and current expected dates for the completion of the project; the original and current cost estimates adjusted for inflation; an explanation for any delays in completing the project or increases in the cost; and the amount of and rationale for any award, incentive fee, or other type of bonus awarded for the project. The act also requires OMB to submit an annual report to Congress containing the information submitted by the agencies and post the report on the OMB website.
Became Public Law No: 119-120.
Bill introduced
Presented to President.
No lobbying report on the 119th Congress cites this bill.
The lobbying table lists Senate LDA quarterly reports (LD-2) that cite this bill by number and cover a quarter of the 119th Congress. An LD-2 names a bill as “H.R. 1234” with no Congress, so a report on another Congress, which can only concern a different bill with the same number, is left out, even when it was filed after this Congress began. The amount is what the registrant reported for the whole filing, across every issue on it, not spending on this bill. Official actions and the bill summary come from Congress.gov, and votes from the roll-call record. This page no longer pairs the bill with members' stock trades: matching lobbying clients to traded companies by name, and trades to a bill by date, is not something the records establish.